At StoneArche by RK Marbles, we blend nature’s elegance with expert craftsmanship — creating spaces that leave a lasting impression.
Shahzadpur, Road, near Anaj Mandi, Saha, Haryana 133104
rkmarblessaha@gmail.com
+91 9416443883
These Terms and Conditions govern your use of our website, services, and any transactions conducted with us. By accessing or using our site, you agree to abide by these terms
At StoneArche, we are committed to bringing your vision to life with unmatched craftsmanship and attention to detail. Our work is defined by the approved quotation, project proposal, or purchase order, and typically includes:
Personalized design consultation to refine your ideas.
Expert material selection and sourcing to ensure premium quality.
Precision fabrication using state-of-the-art techniques.
Professional installation tailored to your exact specifications.
Any additional requests or modifications beyond the agreed scope will require a written variation order. This may involve revised pricing, adjusted timelines, or updated contractual terms—all of which will be clearly communicated and approved by you before we proceed.
All pricing is based on our official quotation, valid for the duration specified. Prices are carefully calculated considering the agreed scope of work, material costs, labor, and other relevant factors.
To begin your project, a non-refundable advance payment (percentage as agreed) is required. The remaining balance will be payable either upon completion or in pre-agreed milestone installments.
Payments must be made through authorized channels. In case of late payments, StoneArche reserves the right to pause work and adjust delivery timelines. Interest charges may apply as per applicable laws.
Client Commitments:
Provide accurate specifications, measurements, and project requirements.
Approve all designs, drawings, and materials in writing before work begins.
Ensure the site is ready, safe, and accessible for delivery and installation.
Secure any necessary permits or approvals for the project.
Our Commitment to You:
Deliver work in strict accordance with approved designs and quality standards.
Use only premium-grade materials as per the agreement.
Maintain the highest level of professionalism, safety, and workmanship.
Keep you updated on progress and respond to queries promptly.
We aim to complete every project within the agreed schedule. Timelines begin once the advance payment is received and all designs and materials are approved in writing.
While we strive to meet deadlines, factors such as material availability, site conditions, or unforeseen events may cause delays. Should this occur, we will promptly inform you and provide revised schedules.
StoneArche is not responsible for delays caused by factors beyond our control, such as natural disasters, strikes, political unrest, delays in client approvals, site inaccessibility, or supply chain disruptions.
If delays occur due to our own oversight, remedies will be considered as per the agreed contract. Both parties agree to work in good faith to minimize any impact on the project timeline.
Our products are crafted with meticulous attention to detail, using premium materials and adhering to industry-best practices. We provide a warranty against manufacturing defects for the duration stated in your agreement.
Please note:
Natural variations in stone color, grain, and texture are part of its beauty and not considered defects.
The warranty does not cover damage due to improper handling, unauthorized alterations, or inadequate maintenance after installation.
Cancellation requests must be submitted in writing within the timeframe specified in the agreement. Costs for materials already purchased or work completed will be deducted from any refundable amount.
Custom or made-to-order products are non-refundable once production has started. Refunds will be processed in line with company policy and applicable banking timelines.
These Terms & Conditions are governed by the laws of Haryana/India. Any disputes will fall under the exclusive jurisdiction of the courts in Shahzadpur/Haryana.
Before pursuing legal action, both parties agree to seek resolution through negotiation or mediation, ensuring a fair and amicable approach.
💎 StoneArche Promise: Every project is more than just work—it’s a partnership built on trust, transparency, and craftsmanship that lasts a lifetime.
StoneArche isn’t just about stone it’s about creating experiences, defining character, and building legacies through every surface we touch.
Shahzadpur, Road, near Anaj Mandi, Saha, Haryana 133104